Loading...
HomeMy WebLinkAboutRES 12-056 RESOLUTION NO. 12-056 BE IT RESOLVED BY THE CITY COUNCIL OF THE CITY OF BEAUMONT: THAT the City Council hereby approves the purchase of a Smart X System Migration, which will bring the City of Beaumont's radio system into Project 25 compliance, from Motorola Solutions, Inc.,of Schaumburg, Illinois, in the amount of$2,495,059 through the Houston-Galveston Area Council (H-GAC) Cooperative Purchasing Program. PASSED BY THE CITY COUNCIL of the City of Beaumont this the 20th day of March, 2012. dd(, ,�v o (14or Becky Ames - hip SYSTEM PURCHASE AGREEMENT(Radio Systems) THIS AGREEMENT ("Agreement') is made and entered into this,&day of March 2012, by and between Motorola Solutions, Inc., a Delaware corporation duly authorized to conduct business in the State of Texas("Motorola"or"Seller")and the City of Beaumont, Texas,a body corporate and politic("Purchaser"). WITNESSETH: WHEREAS,the Purchaser desires to purchase a Communications System;and WHEREAS,Motorola desires to sell a Communications System to Purchaser;and WHEREAS, Houston-Galveston Area Council ("H-GAC"), acting as the agent for various local governmental entities who are "End Users" under interlocal agreements (including the Purchaser) has solicited proposals for radio communications equipment and conducted discussions with Motorola concerning its proposal and,where applicable, in accordance with the competitive procurement procedures of Texas law; and WHEREAS,H-GAC and Motorola entered into that certain Contract dated as of January 1, 2008 (the"Contract"),which provided that End Users may purchase radio communications equipment from Motorola pursuant to certain terms contained therein;and WHEREAS, pursuant to Article 34 of the Contract, Motorola and Purchaser now wish to enter into this System Purchase Agreement to delineate the specific terms of the purchase of radio communications equipment from Motorola by the Purchaser. THEREFORE, the parties hereby enter into an agreement pursuant to which Motorola shall perform the work and furnish the equipment and services as more fully set forth herein and in the following exhibits, which are either attached hereto or incorporated by reference and hereby made a part of this Agreement: Exhibit A General Provisions. Exhibit B Motorola Software License Agreement. Exhibit C Technical and Implementation Documents, consisting of: System Description, Statement of Work and Equipment List all dated February 29,2012. Exhibit D Motorola/H-GAC Contract Exhibit E Warranty and Maintenance Plan and Service Terms and Conditions (if applicable). NOW, THEREFORE, for and in consideration of the mutual promises and covenants contained herein, the parties agree as follows: i Motorola Contract No. -1- System Purchase Agreement 9.8.2011 Section 1 SCOPE OF WORK A. Motorola shall furnish all of the equipment and software as outlined in Exhibit C and provide the tools, supplies, labor and supervision necessary for the installation of the items purchased in accordance with Exhibit C. B. In addition to responsibilities described in the Statement of Work, Purchaser shall perform the following coincident with the performance of this Agreement: (1) Provide a designated Project Director. (2) Provide ingress and egress to Purchaser's facilities and/or sites as requested by Motorola and have such facilities available for installation of the equipment to be installed. (3) Provide adequate telephone or other communications lines(including modem access and adequate interfacing networking capabilities) for the installation, operation and support of the equipment. (4) Provide adequate space, air conditioning and other environmental conditions, and adequate and appropriate electrical power outlets, distribution, equipment and connections for the installation, operation and support of the equipment. (5) Provide a designated work area with adequate heat and light, and a secure storage area for equipment delivered to the Purchaser. The Purchaser shall be solely liable for loss or damage to equipment prior to, during and following installation when such equipment is on or within Purchaser's facilities and/or vehicles. Section 2 SITES This Agreement is predicated on the utilization of sites and site configurations, which have been selected either by the Purchaser or by Motorola and set forth in Exhibit C. In either situation, should it be determined by either Motorola or Purchaser during the course of performance on this Agreement that the sites or configuration selected are no longer available or desired,new or replacement sites or configuration will be selected and approved by both Motorola and the Purchaser. If any price or schedule adjustments are necessary as a result of these new or replacement sites, such adjustments will be added to this Agreement by change order in accordance with Section 4 of the General Provisions. Motorola Contract No. -2- System Purchase Agreement 9.8.2011 I i Section 3 SUBSURFACE/STRUCTURAL CONDITIONS r This Agreement is predicated upon normal soil conditions defined by E.I.A. standard RS-222 (latest revision). Should Motorola encounter subsurface, structural, adverse environmental and/or latent conditions at any site differing from those indicated on the specifications,or as used in the preparation of the bid price, the Purchaser will be given immediate notice of such conditions before they are further disturbed. Thereupon, Motorola and the Purchaser shall promptly investigate the conditions and, if found to be different, will adjust the plans and/or specifications as may be necessary. Any changes that cause an adjustment in the contract price or in time required for the performance of any part of the contract shall result in a contract modification in accordance with Section 4 of the General Provisions. Section 4. PERIOD OF PERFORMANCE A. Motorola projects that it will be able to obtain final acceptance and completion of the Acceptance Test Plan within the time interval specified in Exhibit C (if applicable). A more detailed timeline shall be provided to Purchaser after the design review and customer kick-off meeting. B. Whenever a party knows or reasonably should know that any actual or potential condition due to circumstances beyond its control is delaying or threatens to delay the timely performance of the work, the party shall within thirty (30) days give the other party notice thereof and may request an extension of time to perform the work. C. In order to successfully integrate and implement this project, shipments will be made F.O.B. Destination to Purchaser facilities, local Motorola staging facilities, warehousing facilities, or any combination thereof. It is agreed that this plan is acceptable to Purchaser and that Motorola will advise prior to shipment of actual destination and that Purchaser will accept shipment,and make payment as required by this Agreement. D. It is also agreed that equipment shipping dates reflected in this Agreement are estimates only, and that shipment may be made at any time prior to, or subsequent to these estimated shipping dates. Section 5 ACCEPTANCE CRITERIA A. Motorola will test the Communications System in accordance with the Acceptance Test Plan. System acceptance will occur upon the successful completion of such testing ("System Acceptance) at which time both parties shall promptly execute a certificate of system acceptance. If the Acceptance Test Plan includes separate tests for individual subsystems or phases of the System, both parties shall promptly execute certificates of subsystem acceptance upon the successful completion of testing of such subsystems or phases. Minor omissions or variances in performance which do not materially affect the operation of the Communications System as a whole will not postpone System Acceptance. Purchaser and Motorola will jointly prepare a list of such omissions and variances which Motorola will correct according to an agreed upon schedule. Motorola Contract No. .3- System Purchase Agreement 9.8.2011 B. Motorola agrees to notify Purchaser when the Communications System is ready for acceptance testing. Motorola and Purchaser agree to commence acceptance testing within ten (10) business days after receiving such notification. If testing is delayed for reasons within the control of Purchaser or its employees, contractors, agents or consultants for more than ten (10) business days after notification, final payment will be due within thirty (30) days after such notification and the Warranty Period will commence immediately. C. Motorola may,but is not obligated to, issue written authorization for Purchaser to use the Communications System or its subsystem(s) for limited training or testing purposes, prior to the completion of testing by Motorola. Any use of the Communications System without prior written authorization by Motorola shall constitute System Acceptance. Section 6 PAYMENT SCHEDULE A. Motorola agrees to sell all of the equipment and perform the services as outlined in the Scope of Work, and Purchaser agrees to buy the aforementioned equipment and services for the sum of Two Million Four Hundred Nety Five Thousand Fifty Nine dollars($2,495,059),which includes the H-GAC administration fee. The final price may be adjusted by change orders approved pursuant to Statement of Work attached hereto as Exhibit"C". B. Payments to Motorola shall be made according to the following milestones: 1. 20%of the total contract price is due when Purchaser executes this Agreement; 4 2. 60% of the total contract price will be invoiced immediately after the Equipment is shipped from Motorola's facilities; 3. 10% of the total contract price will be invoiced immediately after the Equipment is installed at the sites specified in the Exhibits; and 4. 10%of the total contract price will be invoiced immediately after System Acceptance. Motorola reserves the right to make partial shipments of equipment and to request payment upon shipment of such equipment. In addition, Motorola reserves the right to invoice for installations or civil work completed on a site-by-site basis,when applicable. C. In the event of failure or delay by the Purchaser in providing sites, space, approvals, licenses, or any other Purchaser obligations required preceding delivery of Motorola equipment, it is agreed that Motorola, at its sole discretion, may ship equipment as planned and that the Purchaser will accept the equipment and make payment in accordance with the terms of this Agreement. Any additional costs incurred by Motorola for storage of equipment will be invoiced and paid by Purchaser. t Motorola Contract No. -4- System Purchase Agreement 9.8.2011 D. Payments to Motorola shall be made as follows: f (i) Motorola shall immediately forward an invoice for the payment requested in Section 6(B)above to Purchaser. (ii) Purchaser shall pay the Motorola invoice within thirty (30) calendar days of receipt. E. Motorola will pay H-GAC's administrative fee in accordance with the payment terms of Motorola/H-GAC Contract dated January 1,2008. F. TERM. Unless terminated in accordance with other provisions of this Agreement or extended by mutual agreement of the Parties, the term of this Agreement begins on the date as set forth above and continues until the date of Final Project Acceptance or expiration of the Warranty Period,whichever occurs last. Section 7 PROJECT MANAGEMENT A. If the size or complexity of the project warrants,Motorola will assign a Project Manager, who is authorized to exercise technical direction of this project. Motorola, at any time, may designate a new or alternate Project Manager with written notice to Purchaser and H-GAC. B. All matters affecting the terms of this Agreement or the administration thereof shall be referred to Motorola's cognizant Contract Administrator who shall have authority to negotiate changes in or amendments to this Agreement. Section 8 NOTICE ADDRESSES A. Motorola Solutions,Inc. 1303 East Algonquin Road Schaumburg,IL 60196 Attn.: Law Department B. City of Beaumont P.O.Box 3827 Beaumont, TX 77704 C. Houston-Galveston Area Council 3555 Timmons Lane, Suite 120 Houston,Texas 77027 Attn.: Public Services Manager Motorola Contract No. -5- System Purchase Agreement 9.8.2011 Section 9 ORDER OF PRECEDENCE In the event of an inconsistency in this Agreement, the inconsistency shall be resolved in the following order: The main body of this Agreement. Exhibit A General Provisions. Exhibit B Motorola Software License. Exhibit C Technical and Implementation Documents. Exhibit E Warranty and Maintenance Plan and Service Terms and Conditions(if applicable) Exhibit D Motorola/H-GAC Contract dated January 1,2008. Section 10 DISPUTES Motorola and the Purchaser will attempt to settle any claim or controversy arising out of this Agreement through consultation and negotiation in good faith and a spirit of mutual cooperation. If those attempts fail, then the dispute will be mediated by a mutually acceptable mediator to be chosen by Motorola and the Purchaser within thirty (30) days after written notice by one of the parties demanding non-binding mediation. Neither party may unreasonably withhold consent to the selection of a mediator. Motorola and the Purchaser will bear their own costs but will share the cost of the mediator equally. By mutual agreement, however, Motorola and Purchaser may postpone mediation until both parties have completed some specified but limited discovery about the dispute. The parties may also agree to replace mediation with some other form of non- binding alternate dispute resolution procedure("ADR"). Any dispute which cannot be resolved between the parties through negotiation or mediation within two (2) months of the date of the initial demand for it by one of the parties may then be submitted to a court of competent jurisdiction in Texas. Both Motorola and Purchaser consent to jurisdiction over it by such a court. All communications pursuant to the negotiation and mediation will be treated as compromise and settlement negotiations for purposes of applicable rules of evidence and any additional confidentiality protections provided by applicable law. The use of any ADR procedures will not be considered under the doctrine of laches, waiver or estoppel to affect adversely the rights of either party. Nothing shall prevent either of the parties from resorting to the judicial proceedings mentioned in this paragraph if(a) good faith efforts to attempt resolution of the dispute under these procedures have been unsuccessful or (b) interim relief from the court is necessary to prevent serious and irreparable injury to one of the parties or others. Motorola Contract No. -6- System Purchase Agreement 9.8.2011 Section 11 SEVERABILITY i If any portion of this Agreement or any exhibits hereto is held to be invalid, such provision or portion of such provision shall be considered severable, and the remainder of this Agreement shall not be affected. Section 12 HEADINGS AND SECTION REFERENCES The headings given to the paragraphs are inserted for convenience only and are in no way to be construed as part of this Agreement or as a limitation of the scope of the particular paragraph to which the heading refers. Section 13 SURVIVAL OF TERMS The following provisions will survive the expiration or termination of this Agreement for any reason: Section 6 (Payment Schedule) if any payment obligations exist; Section 9 (Order of Precedence); Section 10 (Disputes); Section 11 (Severability); Section 12 (Headings and Section References); Section 13 (Survival of Terms)and Section 14(Full Agreement). Section 14 FULL AGREEMENT This Agreement and its Exhibits constitute the final expression of the agreement of the parties and supersedes all previous agreements and understandings, whether written or oral, relating to the work. This Agreement may be executed in multiple counterparts, each of which shall be an original and all of which shall constitute one and the same instrument. A facsimile copy or computer image,such as a PDF or tiff image,or a signature shall be treated as and shall have the same effect as an original signature. In addition, a true and correct facsimile copy or computer image of this Agreement shall be treated as and shall have the same effect as an original signed copy of this document. This Agreement may not be altered, amended, or modified except by written instrument signed by duly authorized representatives of the parties. The preprinted terms and conditions found on any Purchaser purchase order, acknowledgment or other form will not be considered an amendment or modification of this Agreement, even if a representative of each party signs that document. I Motorola Contract No. -7- System Purchase Agreement 9.8.2011 IN WITNESS 'Wk ERWF,the puties have caused this Agreement to be executed by their duly a�ufluvized representatives as ofthe last day and year written below. MOTOROLA SOLUTION. , C. PURCHASER By: By: (signature) (Signature) �` Name: w E Name: (Print-Block Letters) (Print-Block Letters) Motorola Sok tis m Sales and e* i� , e A 4S e� Title: servicm Inc. t Title: (]print-Block Letters) (Print 810ck Letters) Date:February 24.2012 Date: ' i i Motorola Contract No. -8- System Purchase Agreement 9.8.20t't